Legal Opinion
Complete Gen. Constr. Co. v. Ohio Dept. of Transp.
Ohio Supreme Court
Decided January 16, 2002No. 2000-1267PublishedCited by 8 opinions
1Opinion of the Court
[This decision has been published in Ohio Official Reports at 94 Ohio St.3d 54.] COMPLETE GENERAL CONSTRUCTION COMPANY, APPELLEE AND CROSS- APPELLANT, v. OHIO DEPARTMENT OF TRANSPORTATION, APPELLANT AND CROSS-APPELLEE. [Cite as Complete Gen. Constr. Co. v. Ohio Dept. of Transp.,
2002-Ohio-59.] Public construction — Modified Eichleay formula is one way of determining unabsorbed home office overhead damages in public construction delay cases — Courts applying modified Eichleay formula must allow owners opportunity to dispute particular items contractor submits in an overall overhead cost…
2Cases cited13 opinions
- Seasons Coal Co. v. City of ClevelandOhio Supreme Court · 1984
- C. E. Morris Co. v. Foley Construction Co.Ohio Supreme Court · 1978
- Wickham Contracting Co., Inc. v. Dennis J. Fischer, Acting Administrator, General Services AdministrationCourt of Appeals for the Federal Circuit · 1994
- Interstate General Government Contractors, Inc. v. Togo West, Secretary of the ArmyCourt of Appeals for the Federal Circuit · 1993
- City of Gahanna v. Eastgate Properties, Inc.Ohio Supreme Court · 1988
8 more not listed; retrieve them via the Exa API.
3Cited by8 opinions
- American Contractor's Indemnity v. Nicole Gas, 07ap-1039 (9-30-2008)Ohio Court of Appeals · 2008
- Tedla v. Al-ShamrookhOhio Court of Appeals · 2017
- Illum. Co. v. BurnsOhio Court of Appeals · 2014
- Illuminatiny Company v. CochranOhio Court of Appeals · 2018
- Ohio Edison Co. v. HouserOhio Court of Appeals · 2018
3 more not listed; retrieve them via the Exa API.