Legal Opinion
Wickham Contracting Co., Inc. v. Dennis J. Fischer, Acting Administrator, General Services Administration
Court of Appeals for the Federal Circuit
Decided January 6, 1994No. 19-1358PublishedCited by 80 opinions
1Opinion of the Court
MICHEL, Circuit Judge.
Wickham Contracting Company appeals from a decision of the General Services Administration Board of Contract Appeals (Board), denying Wickham’s claim for an equitable adjustment for overhead expenses incurred under a contract with the General Services Administration (GSA) as a result of GSA-imposed delays. Wickham Contracting Co., GSBCA No. 8675, 92-3 BCA ¶ 25,040, 1992 WL 88326 (Apr. 29, 1992). First, the Board held that the Eichleay formula is the proper method for calculating unabsorbed home office overhead when a contractor otherwise satisfies the Eichleay…
2Cases cited8 opinions
- Erickson Air Crane Company of Washington, Inc. v. The United StatesCourt of Appeals for the Federal Circuit · 1984
- Interstate General Government Contractors, Inc. v. Togo West, Secretary of the ArmyCourt of Appeals for the Federal Circuit · 1993
- United States v. General Electric CorporationCourt of Appeals for the Federal Circuit · 1984
- Capital Electric Company v. The United StatesCourt of Appeals for the Federal Circuit · 1984
- C.B.C. Enterprises, Inc. v. The United StatesCourt of Appeals for the Federal Circuit · 1992
3 more not listed; retrieve them via the Exa API.
3Cited by80 opinions
- Nvt Technologies, Inc. v. United StatesCourt of Appeals for the Federal Circuit · 2004
- Overstreet Electric Co. v. United StatesUnited States Court of Federal Claims · 2000
- E.L. Hamm & Associates, Inc. v. Gordon R. England, Secretary of NavyCourt of Appeals for the Federal Circuit · 2004
- E.R. Mitchell Construction Co. v. Richard J. Danzig, Secretary of the NavyCourt of Appeals for the Federal Circuit · 1999
- P.J. Dick Inc. v. PrincipiCourt of Appeals for the Federal Circuit · 2003
75 more not listed; retrieve them via the Exa API.