Legal Opinion
Interstate General Government Contractors, Inc. v. Togo West, Secretary of the Army
Court of Appeals for the Federal Circuit
Decided December 6, 1993No. 92-1430PublishedCited by 78 opinions
1Opinion of the Court
MICHEL, Circuit Judge.
Interstate General Government Contractors, Inc. (IGGC) appeals from a decision of the Armed Services Board of Contract Appeals (Board) denying IGGC’s claim for an equitable adjustment for alleged unabsorbed home office overhead caused by the government’s delay in issuing a notice to proceed (NTP) on a contract to renovate army barracks. Interstate Gen. Gov’t Contractors, Inc., ASBCA No. 43369, 92-2 BCA ¶ 24,956, 1992 WL 59384 (March 17, 1992). The Board first held that IGGC was not entitled to recover pursuant to the Eichleay formula, 1 its sole theory of recovery,…
2Cases cited7 opinions
- Community Heating & Plumbing Company, Inc. v. Admiral Frank B. Kelso, Ii, Acting Secretary of the NavyCourt of Appeals for the Federal Circuit · 1993
- Capital Electric Company v. The United StatesCourt of Appeals for the Federal Circuit · 1984
- C.B.C. Enterprises, Inc. v. The United StatesCourt of Appeals for the Federal Circuit · 1992
- Fruin-Colnon Corporation v. The United StatesCourt of Appeals for the Federal Circuit · 1990
- Daly Construction, Inc. v. H. Lawrence Garrett, Iii, Secretary of the NavyCourt of Appeals for the Federal Circuit · 1993
2 more not listed; retrieve them via the Exa API.
3Cited by78 opinions
- Overstreet Electric Co. v. United StatesUnited States Court of Federal Claims · 2000
- Wickham Contracting Co., Inc. v. Dennis J. Fischer, Acting Administrator, General Services AdministrationCourt of Appeals for the Federal Circuit · 1994
- Howard Contracting, Inc. v. G.A. MacDonald Construction Co.California Court of Appeal · 1999
- E.R. Mitchell Construction Co. v. Richard J. Danzig, Secretary of the NavyCourt of Appeals for the Federal Circuit · 1999
- P.J. Dick Inc. v. PrincipiCourt of Appeals for the Federal Circuit · 2003
73 more not listed; retrieve them via the Exa API.