Legal Opinion
Gladwynne Const. v. Mayor and City Council of Baltimore
Court of Special Appeals of Maryland
Decided September 25, 2002No. 2653 Sept. Term, 2000PublishedCited by 4 opinions
1Opinion of the Court
HOLLANDER, Judge.
This case arises from a construction contract (the “Contract”) between Gladwynne Construction Company (“Gladwynne”), appellant and cross-appellee, and the Mayor and City Council of Baltimore (the “City”), appellee and cross-appellant. The Contract had a “base bid price” of $497,000, and involved the renovation of several classrooms and science laboratories (the “Project”) at Polytechnic High School No. 403 (the “School” or “Poly”). For reasons that are in dispute, the completion of the work was delayed by almost a year.
On October 3, 1999, after the City failed to make full…
2Cases cited27 opinions
- Heat & Power Corp. v. Air Products & Chemicals, Inc.Court of Appeals of Maryland · 1990
- Town of Somerset v. Montgomery County Board of AppealsCourt of Appeals of Maryland · 1966
- Blinderman Construction Co., Inc. v. The United StatesCourt of Appeals for the Federal Circuit · 1982
- Wickham Contracting Co., Inc. v. Dennis J. Fischer, Acting Administrator, General Services AdministrationCourt of Appeals for the Federal Circuit · 1994
- Interstate General Government Contractors, Inc. v. Togo West, Secretary of the ArmyCourt of Appeals for the Federal Circuit · 1993
22 more not listed; retrieve them via the Exa API.
3Cited by4 opinions
- Brendsel v. WINCHESTER CONSTRUCTION CO., INC.Court of Appeals of Maryland · 2006
- Brendsel v. Winchester Construction Co.Court of Special Appeals of Maryland · 2005
- Brendsel v. WINCHESTER CONSTRUCTION CO., INC.Court of Appeals of Maryland · 2006
- Star Development Group, LLC v. Darwin National AssuranceCourt of Appeals for the Fourth Circuit · 2020