Legal Opinion
Blinderman Construction Co., Inc. v. The United States
Court of Appeals for the Federal Circuit
Decided December 10, 1982No. Appeal 53-82PublishedCited by 88 opinions
1Opinion of the Court
COWEN, Senior Circuit Judge.
Pursuant to the Contract Disputes Act of 1978, 41 U.S.C. §§ 601, et seq., the appellant (contractor) appeals from a decision of the Armed Services Board of Contract Appeals (Board) which denied, in part, the contractor’s claim in the amount of $45,312, and its request for a time extension of 13 days for the completion of the contract. The case is before us on cross-motions for summary judgment filed in the United States Court of Claims prior to October 1, 1982, and thereafter transferred to this court.
The claim grows out of a contract entered into between the…
2Cases cited14 opinions
- Arizona ex rel. Arizona Department of Transportation v. United StatesUnited States Court of Claims · 1978
- Commerce International Company, Inc. v. The United StatesUnited States Court of Claims · 1964
- Koppers Company, Inc. v. The United StatesUnited States Court of Claims · 1968
- Ordnance Research, Inc. v. United StatesUnited States Court of Claims · 1979
- Chaney and James Construction Company, Inc. v. The United StatesUnited States Court of Claims · 1970
9 more not listed; retrieve them via the Exa API.
3Cited by88 opinions
- Melvin Wilner, D/B/A Wilner Construction Company v. United StatesCourt of Appeals for the Federal Circuit · 1994
- Mega Construction Co. v. United StatesUnited States Court of Federal Claims · 1993
- Barron Bancshares, Inc. v. United StatesCourt of Appeals for the Federal Circuit · 2004
- Essex Electro Engineers, Inc.,appellant v. Richard J. Danzig, Secretary of the NavyCourt of Appeals for the Federal Circuit · 2000
- Barron Bancshares, Inc. v. United StatesCourt of Appeals for the Federal Circuit · 2004
83 more not listed; retrieve them via the Exa API.