Legal Opinion
Greg Opinski Construction, Inc. v. City of Oakdale
California Court of Appeal
Decided October 6, 2011No. Nos. F060219, F060727PublishedCited by 2 opinions
1Opinion of the Court
Opinion
WISEMAN, Acting P. J.
After a bench trial in this dispute between the City of Oakdale (city) and its general contractor on a building project, Greg Opinski Construction, Inc. (Opinski), the trial court awarded the city $54,000 in liquidated damages for late completion, $3,266 for repair of construction defects, prejudgment interest, and $97,775 in attorneys’ fees. The claims in a cross-complaint by Opinski and its performance bond surety, Fidelity and Deposit Company of Maryland, were rejected.
In its statement of decision, the trial court stated that it would not consider whether the…
2Cases cited7 opinions
- Fassberg Construction Co. v. Housing AuthorityCalifornia Court of Appeal · 2007
- Peter Kiewit Sons' Co. v. Pasadena City Junior College DistrictCalifornia Supreme Court · 1963
- General Insurance Co. of America v. Commerce Hyatt HouseCalifornia Court of Appeal · 1970
- Yassin v. SolisCalifornia Court of Appeal · 2010
- Buckman v. TuckerCalifornia Supreme Court · 1937
2 more not listed; retrieve them via the Exa API.
3Cited by2 opinions
- Pittsburg Unified School District v. S.J. Amoroso Construction Co.California Court of Appeal · 2014
- Gilbane Federal v. United Infrastructure ProjectsCourt of Appeals for the Ninth Circuit · 2019