Introducing ATLASLearn more
Legal Opinion

T.L. Roof & Associates Construction Co. v. United States

United States Court of Federal Claims

Decided July 1, 1993No. 90-538CPublishedCited by 11 opinions

1Opinion of the Court

OPINION

ANDEWELT, Judge.

In this government contract action filed pursuant to the Contract Disputes Act, 41 U.S.C. § 601 et seq. (CDA), plaintiff, T.L. Roof & Associates Construction Company (T.L. Roof), contracted with the United *574States Army Corps of Engineers (the Corps) to construct a two-story Communications Equipment Facility (CEF) at Fort Huachuca, Arizona. Originally, the date for contract completion was April 5, 1989, but as a result of a series of delays and contract modifications, the project was not completed until October 1989. On March 3, 1989, plaintiff filed a claim with the…

2Cases cited32 opinions

  1. Celotex Corp. v. Catrett, Administratrix of the Estate of CatrettSupreme Court of the United States · 1986
  2. Federal Crop Ins. Corp. v. MerrillSupreme Court of the United States · 1947
  3. United States v. SpearinSupreme Court of the United States · 1918
  4. Paul E. Lehman, Inc. v. United StatesUnited States Court of Claims · 1982
  5. Skelly v. United StatesUnited States Court of Claims · 1982

27 more not listed; retrieve them via the Exa API.

3Cited by11 opinions

  1. PCL Construction Services, Inc. v. United StatesUnited States Court of Federal Claims · 2000
  2. Neal & Co. v. United StatesUnited States Court of Federal Claims · 1996
  3. McLain Plumbing & Electrical Service, Inc. v. United StatesUnited States Court of Federal Claims · 1993
  4. C & H Commercial Contractors, Inc. v. United StatesUnited States Court of Federal Claims · 1996
  5. CEMS, Inc. v. United StatesUnited States Court of Federal Claims · 2003

6 more not listed; retrieve them via the Exa API.

Showing a preview — retrieve the full document via the Exa API.

View API DocsGet API Key

Powered by the Exa API