Legal Opinion
C & H Commercial Contractors, Inc. v. United States
United States Court of Federal Claims
Decided April 2, 1996No. 92-728 CPublishedCited by 16 opinions
1Opinion of the Court
OPINION AND ORDER
TURNER, Judge.
Plaintiff brought this action pursuant to the Contract Disputes Act of 1978, 41 U.S.C. §§ 605 & 609, seeking damages for delay and impact costs resulting from several contract modifications and extensions that occurred during performance of a construction contract with the United States Air Force.
This opinion addresses defendant’s motion filed June 27,1995 for partial summary judgment and plaintiffs cross-motion filed July 31,1995 for partial summary judgment. For reasons stated below, we conclude that defendant’s motion for summary judgment with respect to…
2Cases cited25 opinions
- Anderson v. Liberty Lobby, Inc.Supreme Court of the United States · 1986
- Celotex Corp. v. Catrett, Administratrix of the Estate of CatrettSupreme Court of the United States · 1986
- Mingus Constructors, Inc. v. The United StatesCourt of Appeals for the Federal Circuit · 1987
- Sweats Fashions, Inc. v. Pannill Knitting Company, Inc.Court of Appeals for the Federal Circuit · 1987
- Northern Assurance Co. v. Grand View Building Assn.Supreme Court of the United States · 1902
20 more not listed; retrieve them via the Exa API.
3Cited by16 opinions
- CCL Service Corp. v. United StatesUnited States Court of Federal Claims · 2000
- Safeco Credit & Fraley Associates, Inc. v. United StatesUnited States Court of Federal Claims · 1999
- Starflight Boats v. United StatesUnited States Court of Federal Claims · 2001
- K-Con Building Systems, Inc. v. United StatesUnited States Court of Federal Claims · 2012
- Jackson Construction Co. v. United StatesUnited States Court of Federal Claims · 2004
11 more not listed; retrieve them via the Exa API.