Legal Opinion
James Stewart & Co. v. United States
United States Court of Claims
Decided January 7, 1946No. 45394PublishedCited by 16 opinions
1Opinion of the Court
WHITAKER, Judge.
Plaintiff had a contract for the erection of the United States Court House at Foley Square, New York City. It sues for damages for delays due to two things: first, delay in furnishing models for the capitals of columns and pilasters; and, second, in making changes. The defendant admits the delays but denies that they were as long as the plaintiff insists they were. The plaintiff says these two things delayed it a year; defendant says the delay did not exceed 88 days, if so much.
The building is thirty-one stories high. The first six floors occupy substantially all the site. The…
2Cases cited10 opinions
- Severin v. United StatesUnited States Court of Claims · 1943
- United States v. RiceSupreme Court of the United States · 1942
- Brand Inv. Co. v. United StatesUnited States Court of Claims · 1944
- Irwin & Leighton v. United StatesUnited States Court of Claims · 1944
- Magoba Construction Co. v. United StatesUnited States Court of Claims · 1943
5 more not listed; retrieve them via the Exa API.
3Cited by16 opinions
- J. D. Hedin Construction Company, Inc., for Its Own Use and for the Use of Fischbach & Moore, Its Sub-Contractor v. The United StatesUnited States Court of Claims · 1965
- George A. Fuller Co. v. United StatesUnited States Court of Claims · 1947
- F. H. McGraw & Co. v. United StatesUnited States Court of Claims · 1955
- J. L. Simmons Company, Inc., a Corporation v. The United StatesUnited States Court of Claims · 1962
- Warren Bros. Roads Co. v. United StatesUnited States Court of Claims · 1952
11 more not listed; retrieve them via the Exa API.