Legal Opinion
George A. Fuller Co. v. United States
United States Court of Claims
Decided February 3, 1947No. 44585PublishedCited by 118 opinions
1Opinion of the Court
WHITAKER, Judge.
The plaintiff sues the defendant for damages for delays caused by defendant in failing to furnish models on time, for delays caused by changes made in the work, and for delay in the approval of the limestone to be used.
The plaintiff entered into a contract for the erection of the Archives Building in the City of Washington, D. C. Under it the Government agreed to furnish models for the ornamentation of granite, limestone, bronze, plaster, and other materials used in the construction' of the building. There were delays in the furnishing of the models for the granite and…
2Cases cited34 opinions
- United States v. BehanSupreme Court of the United States · 1884
- United States v. GleasonSupreme Court of the United States · 1900
- Columbus Railway, Power & Light Co. v. City of ColumbusSupreme Court of the United States · 1919
- Lovell v. St. Louis Mutual Life InsuranceSupreme Court of the United States · 1884
- United States v. RiceSupreme Court of the United States · 1942
29 more not listed; retrieve them via the Exa API.
3Cited by118 opinions
- United States v. Utah Construction & Mining Co.Supreme Court of the United States · 1966
- Sun Oil Co. v. United StatesUnited States Court of Claims · 1978
- C. Sanchez and Son, Incorporated v. United StatesCourt of Appeals for the Federal Circuit · 1993
- J. D. Hedin Construction Company, Inc., for Its Own Use and for the Use of Fischbach & Moore, Its Sub-Contractor v. The United StatesUnited States Court of Claims · 1965
- Helene Curtis Industries, Inc. v. The United StatesUnited States Court of Claims · 1963
113 more not listed; retrieve them via the Exa API.