Legal Opinion
Community Heating & Plumbing Company, Inc. v. Admiral Frank B. Kelso, Ii, Acting Secretary of the Navy
Court of Appeals for the Federal Circuit
Decided March 11, 1993No. 92-1362PublishedCited by 196 opinions
1Opinion of the Court
BENNETT, Senior Circuit Judge.
This is an appeal from a decision of the Armed Services Board of Contract Appeals (board) denying the claims brought by Community Heating and Plumbing Co., Inc. (Community), against the Secretary of the United States Navy (Navy). 1 The claims arose out of a contract to remove and replace the condensate and steam system located at the Marine Corps Air Station, Cherry Point, North Carolina. Community seeks compensation for; 1) the costs associated with the installation of conduit sleeves in existing manholes; and, 2) the costs which arose from delays experienced by…
2Cases cited33 opinions
- Fortec Constructors v. The United StatesCourt of Appeals for the Federal Circuit · 1985
- Beacon Construction Co. of Massachusetts v. United StatesUnited States Court of Claims · 1963
- J. D. Hedin Construction Company, Inc., for Its Own Use and for the Use of Fischbach & Moore, Its Sub-Contractor v. The United StatesUnited States Court of Claims · 1965
- Newsom v. United StatesUnited States Court of Claims · 1982
- Brock & Blevins Company, Inc. v. The United StatesUnited States Court of Claims · 1965
28 more not listed; retrieve them via the Exa API.
3Cited by196 opinions
- Blue & Gold Fleet, L.P. v. United StatesCourt of Appeals for the Federal Circuit · 2007
- Nvt Technologies, Inc. v. United StatesCourt of Appeals for the Federal Circuit · 2004
- Grumman Data Systems Corporation v. John H. Dalton, Secretary of the Navy, and Intergraph Corporation, IntervenorCourt of Appeals for the Federal Circuit · 1996
- Metric Constructors, Inc. v. National Aeronautics and Space AdministrationCourt of Appeals for the Federal Circuit · 1999
- John H. Dalton, Secretary of the Navy v. Cessna Aircraft CompanyCourt of Appeals for the Federal Circuit · 1996
191 more not listed; retrieve them via the Exa API.