Mega Construction Co. v. United States

OPINION

MOODY R. TIDWELL, III, Judge:

On August 20,1985, plaintiff, Mega Construction, Inc., entered into a fixed-price construction contract with defendant, through the United States Postal Service, for the construction of the Main Post Office at Canoga Park, California. The contract price was $2,094,900.00, later amended to $2,316,609.68. On September 9, 1985, the Postal Service issued its Notice To Proceed, and on September 17, 1985, Mega commenced work on the project. Originally planned for completion on October 20, 1986, the parties agreed to extend the completion date several times,…