Legal Opinion
M. Maropakis Carpentry, Inc. v. United States
United States Court of Federal Claims
Decided October 3, 2008No. 03-2825CPublishedCited by 7 opinions
1Opinion of the Court
OPINION
BASKIR, Judge.
The plaintiff, M. Maropakis Carpentry, Inc. (Maropakis), alleges breach of contract against the U.S. Department of the Navy. Citing various “delays, impacts and disruptions,” plaintiff seeks damages resulting from the Navy’s denial of Maropakis’s request to extend the time for completion of a construction project pursuant the contract. See Complaint (Compl.). at 1114; First Amended Complaint (Am. Compl.) at 110. The plaintiff moves for partial summary judgment, under the provisions of Rule 56(c) of the Rules for the U.S. Court of Federal Claims (RCFC), leaving the precise…
2Cases cited52 opinions
- Anderson v. Liberty Lobby, Inc.Supreme Court of the United States · 1986
- Celotex Corp. v. Catrett, Administratrix of the Estate of CatrettSupreme Court of the United States · 1986
- Scheuer v. RhodesSupreme Court of the United States · 1974
- McNutt v. General Motors Acceptance Corp.Supreme Court of the United States · 1936
- Karen S. Reynolds v. Army and Air Force Exchange ServiceCourt of Appeals for the Federal Circuit · 1988
47 more not listed; retrieve them via the Exa API.
3Cited by7 opinions
- M. Maropakis Carpentry, Inc. v. United StatesCourt of Appeals for the Federal Circuit · 2010
- Sikorsky Aircraft Corp. v. United StatesUnited States Court of Federal Claims · 2011
- K-Con Building Systems, Inc. v. United StatesUnited States Court of Federal Claims · 2014
- ECC CENTCOM Constructors, LLCArmed Services Board of Contract Appeals · 2018
- H&M Associates, LLC. v. United StatesUnited States Court of Federal Claims · 2023
2 more not listed; retrieve them via the Exa API.