City of Seattle v. Dyad Construction, Inc.

This case concerns the interpretation of a public works contract. It involves a claim for damages by the contractor for delays claimed to have been caused by the municipal corporation. Dyad Construction, Inc. (hereinafter called the contractor), appeals from a judgment entered denying its counterclaim for recovery of delay damages in an action initiated by the municipality, the City of Seattle (hereinafter called the City), for recovery of moneys asserted to have been erroneously paid to the contractor. The City cross-appeals from that portion of the judgment in the same action that awarded…