Legal Opinion
State Highway Administration v. Greiner Engineering Sciences, Inc.
Court of Special Appeals of Maryland
Decided July 3, 1990No. 1677, September Term, 1989PublishedCited by 25 opinions
1Opinion of the Court
BISHOP, Judge.
Greiner Engineering Sciences, Inc., appellee, made a claim against the State Highway Administration (SHA), appellant, for $148,859.80 in delay damages incurred during preparation of construction contract documents for a highway project. Upon denial of its claim, appellee appealed to the Maryland State Board of Contract Appeals 1 (BCA) which, following a de novo hearing, issued a written decision awarding appellee $111,644.00. The Circuit Court for Baltimore County (Turnbull, J.) affirmed the BCA decision.
ISSUES
Appellant asks this Court:
I. Whether the BCA erred by rewriting the…
2Cases cited30 opinions
- Hume v. United StatesSupreme Court of the United States · 1889
- General Motors Acceptance Corp. v. DanielsCourt of Appeals of Maryland · 1985
- Corinno Civetta Construction Corp. v. City of New YorkNew York Court of Appeals · 1986
- E. C. Ernst, Inc. v. Manhattan Construction Company of Texas, Providence Hospital, Fairbanks-Morse, Inc., Charles H. McCauley Associates, Inc.Court of Appeals for the Fifth Circuit · 1977
- E. C. Ernst, Inc. v. Manhattan Construction Company of Texas, Providence Hospital, Fairbanks-Morse, Inc., Charles H. McCauley Associates, Inc.Court of Appeals for the Fifth Circuit · 1977
25 more not listed; retrieve them via the Exa API.
3Cited by25 opinions
- Martin Marietta Corporation v. International Telecommunications Satellite OrganizationCourt of Appeals for the Fourth Circuit · 1993
- Zachry Construction Corporation v. Port of Houston Authority of Harris County, TexasTexas Supreme Court · 2014
- J.A. Jones Construction Co. v. Lehrer McGovern Bovis, Inc.Nevada Supreme Court · 2004
- In Re WechslerDistrict Court, D. Delaware · 2000
- United States ex rel. Tennessee Valley Marble Holding Co. v. Grunley ConstructionDistrict Court, District of Columbia · 2006
20 more not listed; retrieve them via the Exa API.