Legal Opinion
Melvin Wilner, D/B/A Wilner Construction Company v. United States
Court of Appeals for the Federal Circuit
Decided May 26, 1994No. 92-5161PublishedCited by 148 opinions
1Opinion of the Court
SCHALL, Circuit Judge.
The United States appeals from the June 26, 1992 judgment of the United States Claims Court.1 Following a trial, the Claims Court (i) awarded Melvin Wilner, d/b/a Wil-ner Construction Company (Wilner), an additional $26,271.49 plus interest on his claim for delay compensation under the Contract Disputes Act of 1978 (CDA), 41 U.S.C. §§ 601-613 (1988 & Supp. IV 1992); and (ii) denied the government’s claim for the return of certain sums previously paid to Wilner.2 On May 24, 1993, a divided panel of this court affirmed the judgment of the Claims Court.3 The government…
2Cases cited12 opinions
- Renegotiation Board v. Bannercraft Clothing Co.Supreme Court of the United States · 1974
- J. D. Hedin Construction Company, Inc., for Its Own Use and for the Use of Fischbach & Moore, Its Sub-Contractor v. The United StatesUnited States Court of Claims · 1965
- Servidone Construction Corporation, Plaintiff/cross-Appellant v. The United StatesCourt of Appeals for the Federal Circuit · 1991
- Blinderman Construction Co., Inc. v. The United StatesCourt of Appeals for the Federal Circuit · 1982
- G.M. Shupe, Inc. v. United StatesUnited States Court of Claims · 1984
7 more not listed; retrieve them via the Exa API.
3Cited by148 opinions
- Holmes v. United StatesCourt of Appeals for the Federal Circuit · 2011
- Essex Electro Engineers, Inc.,appellant v. Richard J. Danzig, Secretary of the NavyCourt of Appeals for the Federal Circuit · 2000
- North Star Alaska Housing Corp. v. United StatesUnited States Court of Federal Claims · 2007
- Morrison Knudsen Corp. v. Fireman's Fund InsuranceCourt of Appeals for the Tenth Circuit · 1999
- United States v. Oscar RendaCourt of Appeals for the Fifth Circuit · 2013
143 more not listed; retrieve them via the Exa API.