Legal Opinion
Essex Electro Engineers, Inc.,appellant v. Richard J. Danzig, Secretary of the Navy
Court of Appeals for the Federal Circuit
Decided August 18, 2000No. 99-1480PublishedCited by 82 opinions
1Opinion of the Court
BRYSON, Circuit Judge.
Essex Electro Engineers, Inc., appeals from a decision of the Armed Services Board of Contract Appeals. The Board held that Essex was entitled to compensation for certain government-caused delays to its contract performance. For other government-caused delays, however, the Board held that Essex was not entitled to compensation, because it found that Essex concurrently delayed the performance of the contract. We conclude that the parties’ delays in this case may be apportiona-ble; we therefore vacate the Board’s decision and remand for further consideration of that issue.
I
2Cases cited17 opinions
- United States v. SpearinSupreme Court of the United States · 1918
- Emily Malone D/B/A Precision Cabinet Company v. The United StatesCourt of Appeals for the Federal Circuit · 1988
- J. D. Hedin Construction Company, Inc., for Its Own Use and for the Use of Fischbach & Moore, Its Sub-Contractor v. The United StatesUnited States Court of Claims · 1965
- Melvin Wilner, D/B/A Wilner Construction Company v. United StatesCourt of Appeals for the Federal Circuit · 1994
- Commerce International Company, Inc. v. The United StatesUnited States Court of Claims · 1964
12 more not listed; retrieve them via the Exa API.
3Cited by82 opinions
- Rick's Mishroom Service, Inc. v. United StatesCourt of Appeals for the Federal Circuit · 2008
- Precision Pine & Timber, Inc. v. United StatesCourt of Appeals for the Federal Circuit · 2010
- Centex Corp. v. United StatesCourt of Appeals for the Federal Circuit · 2005
- Donald H. Rumsfeld, Secretary of Defense v. Freedom Ny, Inc., Freedom Ny, Inc. v. Donald H. Rumsfeld, Secretary of DefenseCourt of Appeals for the Federal Circuit · 2003
- North Star Alaska Housing Corp. v. United StatesUnited States Court of Federal Claims · 2007
77 more not listed; retrieve them via the Exa API.