Gillioz v. State Highway Commission

This is an action in three counts, as follows: Count I to recover $32,500 deducted from the amount due plaintiff, under his contract for reconstruction of the Inter-City Viaduct in Kansas City, for liquidated damages (at the rate of $500 per day) for failure to complete the viaduct for traffic within the specified time; Count II to recover $57,515.67 as damages claimed to have been caused by reason of delays in the work due to the fault of defendant; and Count III to recover $28,609.80 as damages to plaintiff's subcontractor alleged to be due to same causes claimed in Count II, this claim…