J.A. Jones Construction Co. v. Lehrer McGovern Bovis, Inc.

OPINION

This appeal concerns a dispute over a contract for structural concrete work at the Sands Exposition Center. Although subcontractor J.A. Jones Construction Company obtained a judgment for $1,152,912 against the. construction management contractor, Lehrer McGovern Bovis, Inc. (LMB), Jones asserts that various district court errors resulted in an inadequate judgment.

We conclude that the district court erred in refusing to instruct the jury on exceptions to enforcement of “no damages for delay” clauses in construction contracts, and in dismissing Jones’s claim of cardinal…