BECO Construction Co. v. J-U-B Engineers, Inc.

J. JONES, Justice.

BECO Construction filed suit against JU-B Engineers, claiming that J-U-B had delayed BECO’s work on a construction project, thereby subjecting it to liability for liquidated damages. The district court dismissed BECO’s complaint on summary judgment and awarded attorney fees to JU-B. BECO appeals the dismissal of its claim that J-U-B intentionally interfered with its construction contract, as weE as the fee award. We affirm the grant of summary judgment but vacate a portion of the fee award.

I

In November 2003, the Pocatello Development Authority hired J-U-B Engineers, Inc., to…