Weaver-Bailey Contractors, Inc. v. United States

ORDER

SMITH, Chief Judge.

In its February 9, 1990 opinion, the court awarded plaintiff Weaver-Bailey Contractors an equitable adjustment of $469,041 for increased costs of contract performance. Weaver-Bailey Contractors v. United States, 19 Cl.Ct. 474 (1990). The court found that the government’s defective specifications led to a delay in completing the contract, and concluded that plaintiff’s increased costs stemming from the delay were compensable under the contract’s Differing Site Conditions clause. Defendant now asks the court to reconsider its ruling, asserting, as it did in its…