AMX Enterprises, L.L.P. v. Master Realty Corp.

OPINION ON REHEARING

ANNE GARDNER, Justice.

We grant Appellant AMX Enterprises, L.L.P.’s motion for rehearing in part, deny it in part, withdraw our opinion and judgment of January 8, 2009, and substitute the following. The only changes from our original opinion are the additions of this paragraph and the last sentence of this opinion on rehearing.

Among the issues in this case are three questions of first impression: Whether a trial court may toll the accrual of statutory interest under the Prompt Payment to Contractors Act 1 for periods of delay attributable to the claimant; whether a…