Legal Opinion
Baltimore Contractors, Inc. v. United States
United States Court of Claims
Decided April 30, 1987No. 272-70PublishedCited by 5 opinions
1Opinion of the Court
OPINION
MOODY R. TIDWELL, III, Judge:
On June 1, 1964, the United States, acting through the Architect of the Capitol (Architect) in his role as contracting officer, issued an invitation for bids for the construction of two underground parking garages and related facilities in Washington, D.C. Plaintiff, Baltimore Contractors, Inc., was awarded Contract No. ACho-264 for a fixed price of $11,770,000 on August 10, 1964. A variety of alleged changed conditions, changes to the contract, and delay claims were filed throughout the con*331struction of the garages, requesting an equitable adjustment to the…
2Cases cited32 opinions
- United States v. SpearinSupreme Court of the United States · 1918
- WPC Enterprises, Inc. v. United StatesUnited States Court of Claims · 1963
- Commerce International Company, Inc. v. The United StatesUnited States Court of Claims · 1964
- The Firestone Tire & Rubber Company v. The United StatesUnited States Court of Claims · 1971
- Foster Construction C. A. And Williams Brothers Company, a Joint Venture, Etc. v. The United StatesUnited States Court of Claims · 1970
27 more not listed; retrieve them via the Exa API.
3Cited by5 opinions
- Spirit Leveling Contractors v. United StatesUnited States Court of Claims · 1989
- AAB Joint Venture v. United StatesUnited States Court of Federal Claims · 2007
- North Star Alaska Housing Corp. v. United StatesUnited States Court of Federal Claims · 1993
- CEMS, Inc. v. United StatesUnited States Court of Federal Claims · 2003
- Concrete Placing Co. v. United StatesUnited States Court of Claims · 1992