Legal Opinion
Hensler v. City of Los Angeles
California Court of Appeal
Decided March 23, 1954No. Civ. 19810PublishedCited by 39 opinions
1Opinion of the CourtFox, J.
Defendant appeals from a judgment awarding damages for breach of contract and reimbursing plaintiff for expenditures incident to a suspension of work ordered by defendant.
Plaintiff, a licensed general contractor, entered into a contract with the city of Los Angeles on April 12, 1951, whereby he undertook “to furnish all equipment, material and labor necessary for the construction of, and to construct Stage 1 Runways and Taxiways and appurtenant work at the Los Angeles International Airport.” The total agreement between the parties embraced the following documents, which had been furnished to…
2Cases cited33 opinions
- M. F. Kemper Construction Co. v. City of Los AngelesCalifornia Supreme Court · 1951
- McConnell v. Corona City Water Co.California Supreme Court · 1906
- Powers v. Board of Public WorksCalifornia Supreme Court · 1932
- J. S. Potts Drug Co. v. BenedictCalifornia Supreme Court · 1909
- McMaster v. . the State of New YorkNew York Court of Appeals · 1888
28 more not listed; retrieve them via the Exa API.
3Cited by39 opinions
- Stanley Clayman and Melvin Clayman v. Goodman Properties, IncCourt of Appeals for the D.C. Circuit · 1974
- Howard Contracting, Inc. v. G.A. MacDonald Construction Co.California Court of Appeal · 1999
- Smith v. ZeppMontana Supreme Court · 1977
- Juengel Const. Co., Inc. v. Mt. Etna, Inc.Missouri Court of Appeals · 1981
- McGrath v. Electrical Construction Co.Oregon Supreme Court · 1961
34 more not listed; retrieve them via the Exa API.