Legal Opinion
Melvin Wilner, D/B/A Wilner Construction Company v. The United States
Court of Appeals for the Federal Circuit
Decided August 2, 1993No. 92-5161PublishedCited by 6 opinions
1Opinion of the Court
BENNETT, Senior Circuit Judge.
The United States (government) appeals from a decision1 of the United States Claims Court (Claims Court)2. The Claims Court (1) altered the contracting officer’s calculations to increase the quantum of delay damages awarded to Melvin Wilner, d/b/a Wilner Construction Company (Wilner), by $26,-271.49 plus interest, (2) denied a claim for further delay compensation asserted by Wil-ner, and (3) rejected the government’s claims for repayment of $133,094.79 in delay compensation already paid to Wilner. We affirm.
BACKGROUND
Wilner was engaged by the government to…
2Cases cited22 opinions
- South Corporation and Seal Fleet, Inc. v. The United StatesCourt of Appeals for the Federal Circuit · 1982
- Caci, Inc.-Federal v. The United StatesCourt of Appeals for the Federal Circuit · 1983
- J. D. Hedin Construction Company, Inc., for Its Own Use and for the Use of Fischbach & Moore, Its Sub-Contractor v. The United StatesUnited States Court of Claims · 1965
- Commerce International Company, Inc. v. The United StatesUnited States Court of Claims · 1964
- George A. Fuller Co. v. United StatesUnited States Court of Claims · 1947
17 more not listed; retrieve them via the Exa API.
3Cited by6 opinions
- Melvin Wilner, D/B/A Wilner Construction Company v. United StatesCourt of Appeals for the Federal Circuit · 1994
- Mega Construction Co. v. United StatesUnited States Court of Federal Claims · 1993
- Aircraft Gear Corp. v. Kaman Aerospace Corp.District Court, N.D. Illinois · 1995
- Renda Marine, Inc. v. United StatesUnited States Court of Federal Claims · 2005
- Melvin Wilner, D/B/A Wilner Construction Company v. The United StatesCourt of Appeals for the Federal Circuit · 1993
1 more not listed; retrieve them via the Exa API.