Legal Opinion
Ordnance Research, Inc. v. United States
United States Court of Claims
Decided October 17, 1979No. 161-77PublishedCited by 58 opinions
1Per curiam
This Wunderlich review case is before the court on the parties’ exceptions to the decision of Trial Judge Wood, filed July 27, 1978.
Plaintiff, Ordnance Research, Inc., (ORI) claims recovery for increased costs resulting from what it termed the government’s defective specifications under a Navy contract for production of MK 273 Mod 0 igniters used in fire bombs. Six explosions occurred during production and resulted in delay and increased costs for ORI, not to mention a loss of life. The decision of the Armed Services Board of Contract Appeals (ASBCA), which was limited to the issue of…
2Cases cited23 opinions
- United States v. SpearinSupreme Court of the United States · 1918
- J. D. Hedin Construction Company, Inc., for Its Own Use and for the Use of Fischbach & Moore, Its Sub-Contractor v. The United StatesUnited States Court of Claims · 1965
- Koppers Company, Inc. v. The United StatesUnited States Court of Claims · 1968
- Blount Brothers Construction Company v. The United StatesUnited States Court of Claims · 1965
- Joseph Sternberger, Trustee in Bankruptcy for Spenco, Inc. v. The United StatesUnited States Court of Claims · 1968
18 more not listed; retrieve them via the Exa API.
3Cited by58 opinions
- Rick's Mishroom Service, Inc. v. United StatesCourt of Appeals for the Federal Circuit · 2008
- Blinderman Construction Co., Inc. v. The United StatesCourt of Appeals for the Federal Circuit · 1982
- Essex Electro Engineers, Inc.,appellant v. Richard J. Danzig, Secretary of the NavyCourt of Appeals for the Federal Circuit · 2000
- Granite Construction Company v. The United StatesCourt of Appeals for the Federal Circuit · 1992
- Dewey Electronics Corp. v. The United StatesCourt of Appeals for the Federal Circuit · 1986
53 more not listed; retrieve them via the Exa API.