Degenaars Co. v. United States

OPINION

NETTESHEIM, Judge.

In a proceeding before the Armed Services Board of Contract Appeals (“ASBCA” or the “Board”), Degenaars Company (“De-genaars”) sought an equitable adjustment based on delay and extra work performed in connection with a fixed-price contract to install certain paving and sewage draining systems at the Special Weapons Pilot Plant at Picatinny Arsenal, Dover, New Jersey. Rae Construction Co., Inc. (“plaintiff” or “Rae”), is the real party in interest, having subcontracted for the work at issue and having succeeded to Degenaars’ claim pursuant to a settlement between the…