Legal Opinion
Martin K. Eby Construction Co. v. LAN/STV
Texas Court of Appeals, 5th District (Dallas)
Decided August 29, 2011No. 05-09-00946-CVPublishedCited by 6 opinions
1Opinion of the Court
OPINION
Opinion By
Justice LANG.
Martin K. Eby Construction Co. (Eby) appeals from a trial court’s judgment following a jury trial. In the trial court, Eby sought damages for delays and increased costs it alleged were caused by LAN/STV, a Joint Venture of Lockwood, Andrews & Newnam, Inc. and STV, Incorporated’s (LAN/STV) negligent misrepresentations regarding construction plans prepared for a light rail line project by LAN/STV and others. Eby raises three issues contending the trial court erred by: (1) failing to disregard the findings that Eby was negligent and responsible for fifteen percent…
2Cases cited28 opinions
- City of Keller v. WilsonTexas Supreme Court · 2005
- King Ranch, Inc. v. ChapmanTexas Supreme Court · 2003
- Formosa Plastics Corp. USA v. Presidio Engineers and Contractors, Inc.Texas Supreme Court · 1998
- Lee Lewis Construction, Inc. v. HarrisonTexas Supreme Court · 2002
- Southwestern Bell Telephone Co. v. DeLanneyTexas Supreme Court · 1991
23 more not listed; retrieve them via the Exa API.
3Cited by6 opinions
- lan/stv, a Joint Venture of Lockwood, Andrews & Newman, Inc. and Stv Incorporated v. Martin K. Eby Construction Company, Inc.Texas Supreme Court · 2014
- Cheryl Harris v. Kellogg Brown & Root ServicesCourt of Appeals for the Third Circuit · 2013
- TIB-The Independent BankersBank v. Canyon Community BankDistrict Court, N.D. Texas · 2014
- May v. Apache Corp.District Court, S.D. Texas · 2012
- Joyce Steel Erection, Ltd. v. Gordon Ray BonnerCourt of Criminal Appeals of Texas · 2015
1 more not listed; retrieve them via the Exa API.