Legal Opinion
Aetna Casualty & Surety Co. v. Board of Trustees
California Court of Appeal
Decided December 16, 1963No. Civ. 20849PublishedCited by 7 opinions
1Opinion of the CourtTaylor, J.
Appellants, the Rincon Valley Union School District of Sonoma County and its Board of Trustees (hereinafter referred to as the District), contracted with Frank S. Glover, doing business as Glover Construction Company (hereinafter referred to as the contractor), for the construction of the Spring Creek Elementary School. The agreement established August 29, 1958, as the completion date and contained a clause stipulating $50 liquidated damages for each day the project remained incomplete. The architect granted an extension to October 3, 1958. The work was not completed within the extended time.…
2Cases cited8 opinions
- United States v. United Engineering & Contracting Co.Supreme Court of the United States · 1914
- Jefferson Hotel Co. v. BrumbaughCourt of Appeals for the Fourth Circuit · 1909
- Gogo v. Los Angeles County Flood Control DistrictCalifornia Court of Appeal · 1941
- Peter Kiewit Sons' Co. v. Pasadena City Junior College DistrictCalifornia Supreme Court · 1963
- King Iron Bridge & Manuf'g Co. v. City of St. LouisU.S. Circuit Court for the District of Eastern Missouri · 1890
3 more not listed; retrieve them via the Exa API.
3Cited by7 opinions
- Buckley & Co., Inc. v. StateNew Jersey Superior Court Appellate Division · 1975
- General Insurance Co. of America v. Commerce Hyatt HouseCalifornia Court of Appeal · 1970
- Jasper Construction, Inc. v. Foothill Junior College DistrictCalifornia Court of Appeal · 1979
- Central Steel Drum Co. v. Gold Cooperage, Inc.New Jersey Superior Court Appellate Division · 1985
- Utica Mut. Ins. Co. v. DiDonatoNew Jersey Superior Court Appellate Division · 1982
2 more not listed; retrieve them via the Exa API.