Legal Opinion
Hannon Electric Co. v. United States
United States Court of Federal Claims
Decided April 29, 1994No. 90-3834CPublishedCited by 14 opinions
1Opinion of the Court
*138OPINION
BRUGGINK, Judge.
This action, brought pursuant to the Contract Disputes Act of 1978 (“CDA”), 41 U.S.C. §§ 601-613 (1988), is before the court following trial. The contractor, Hannon Electric Company was default terminated before the contract’s completion date for failure to make progress. Hannon has brought suit seeking to have the default set aside. Trial was held February 7-10, 1994, in Cleveland. For the following reasons the court sustains the default.
BACKGROUND FACTS 1
On July 20, 1988, the Navy awarded Han-non Electric contract number N00406-88-C-1098, which was a contract to build…
2Cases cited21 opinions
- Lisbon Contractors, Inc. v. The United StatesCourt of Appeals for the Federal Circuit · 1987
- Beacon Construction Co. of Massachusetts v. United StatesUnited States Court of Claims · 1963
- Miller Elevator Co. v. United StatesUnited States Court of Federal Claims · 1994
- Maxwell Dynamometer Co. v. United StatesUnited States Court of Claims · 1967
- Granite Construction Company v. The United StatesCourt of Appeals for the Federal Circuit · 1992
16 more not listed; retrieve them via the Exa API.
3Cited by14 opinions
- Driggs Corp. v. Maryland Aviation AdministrationCourt of Appeals of Maryland · 1998
- SIPCO Services & Marine Inc. v. United StatesUnited States Court of Federal Claims · 1998
- Morganti National, Inc. v. United StatesUnited States Court of Federal Claims · 2001
- CJP Contractors, Inc. v. United StatesUnited States Court of Federal Claims · 1999
- NCLN20, Inc. v. United StatesUnited States Court of Federal Claims · 2011
9 more not listed; retrieve them via the Exa API.