RPR & Associates, Inc. v. State

LEWIS, Judge.

RPR & Associates, Inc. (“RPR”) entered into a written construction contract with the State of North Carolina (“State”), through the University of North Carolina at Chapel Hill (“UNC-CH”), to construct the George Watts Hill Alumni Center (“Alumni Center”) on the UNC-CH campus. Following the completion of the Alumni Center, on 22 November 1994, plaintiff filed a verified claim against UNC-CH with the Office of State Construction (“OSC”) pursuant to N.C. Gen. Stat. § 143-135.3(c), seeking to recover costs incurred and an extension of time for completion associated with the delayed…