Legal Opinion
United States Ex Rel. Gillioz v. John Kerns Const. Co.
Court of Appeals for the Eighth Circuit
Decided February 10, 1944No. Civil Action 12717PublishedCited by 27 opinions
1Opinion of the Court
HULEN, District Judge.
Appellant in this case sued for a balance due for work performed under a sub-contract with appellee John Kerns Construction Company. Appellees answered with a counter-claim, alleging there was due from appellant liquidated damages for failure to complete the work called for by subcontract within the time specified.
The case was tried without a jury. The parties stipulated there was due appellant $14,023.86. The contest is on the counterclaim. The Court found for the Construction Company on its counter-claim in the sum of $34,750 and awarded judgment in its favor for the…
2Cases cited17 opinions
- United States v. RiceSupreme Court of the United States · 1942
- United States v. Callahan Walker Construction Co.Supreme Court of the United States · 1942
- Guerini Stone Co. v. P. J. Carlin Construction Co.Supreme Court of the United States · 1919
- United States v. United Engineering & Contracting Co.Supreme Court of the United States · 1914
- Concordia Ins. Co. of Milwaukee v. School Dist. No. 98 of Payne Cty.Supreme Court of the United States · 1931
12 more not listed; retrieve them via the Exa API.
3Cited by27 opinions
- Southwest Engineering Co. v. Reorganized School District R-9Missouri Court of Appeals · 1968
- Midland Engineering Co. v. John A. Hall Construction Co.District Court, N.D. Indiana · 1975
- Flour Mills of America, Inc. v. American Steel Building Co.Supreme Court of Oklahoma · 1969
- Southern Fireproofing Company v. R. F. Ball Construction Company, Inc., Southwest Ball Construction Company and National Surety CorporationCourt of Appeals for the Eighth Circuit · 1964
- Wiebe Construction Co. v. School District of MillardNebraska Supreme Court · 1977
22 more not listed; retrieve them via the Exa API.