Legal Opinion
Biemann & Rowell Co. v. Donohoe Companies
Court of Appeals of North Carolina
Decided November 20, 2001No. COA00-1177PublishedCited by 14 opinions
1Opinion of the Court
THOMAS, Judge.
This breach of contract case between prime contractors is based on a claim of delay in the construction of the University of North Carolina Neuropsychiatric Hospital on the Chapel Hill campus. Plaintiff, Biemann and Rowell Company, was the heating and ventilating contractor, while defendant, The Donohoe Companies, Inc., D/B/A Donohoe Construction Company, was the general contractor.
In a bench trial, the trial court entered judgment in favor of defendant on all of plaintiffs claims. Plaintiff appeals, advancing the following four arguments: (1) the trial court erred in its…
2Cases cited14 opinions
- Servidone Construction Corporation, Plaintiff/cross-Appellant v. The United StatesCourt of Appeals for the Federal Circuit · 1991
- James A. Boyajian, Assignee of Triumph Manufacturing Company, Bankrupt v. The United StatesUnited States Court of Claims · 1970
- Blinderman Construction Co., Inc. v. The United StatesCourt of Appeals for the Federal Circuit · 1982
- F. H. McGraw & Co. v. United StatesUnited States Court of Claims · 1955
- Urban Plumbing & Heating Co., an Oregon Corporation v. The United StatesUnited States Court of Claims · 1969
9 more not listed; retrieve them via the Exa API.
3Cited by14 opinions
- RPR & Associates, Inc. v. University of North Carolina-Chapel HillCourt of Appeals of North Carolina · 2002
- County of Moore v. Humane Society of Moore County, Inc.Court of Appeals of North Carolina · 2003
- D.W.H. Painting Co. v. D.W. Ward Construction Co.Court of Appeals of North Carolina · 2005
- Cleveland Construction, Inc. v. Ellis-Don Construction, Inc.Court of Appeals of North Carolina · 2011
- Carolina First Bank v. Stark, Inc.Court of Appeals of North Carolina · 2008
9 more not listed; retrieve them via the Exa API.