Legal Opinion
John E. Green Plumbing and Heating Company, Inc. v. Turner Construction Company
Court of Appeals for the Sixth Circuit
Decided August 29, 1984No. 83-1116PublishedCited by 47 opinions
1Opinion of the Court
BOYCE F. MARTIN, Jr., Circuit Judge.
In this diversity case, Green Plumbing and Heating appeals the district court’s summary judgment and directed verdict in favor of Turner Construction Company. The main issues on appeal are the effect to be given a “no-damage-for-delay” clause in Green’s construction contract with the City of Detroit and the adequacy of Green’s proof of damages.
Green Plumbing was the plumbing and fire-sprinkler contractor for construction of the new Detroit General Hospital. Turner Construction was the construction manager for the project. As such, its duties included…
2Cases cited10 opinions
- Williams v. PolgarMichigan Supreme Court · 1974
- E. C. Ernst, Inc. v. Manhattan Construction Company of Texas, Providence Hospital, Fairbanks-Morse, Inc., Charles H. McCauley Associates, Inc.Court of Appeals for the Fifth Circuit · 1977
- Jacob Lichter and Jennie L. Lichter, Partners, Doing Business as Southern Fireproofing Company v. Mellon-Stuart CompanyCourt of Appeals for the Third Circuit · 1962
- Peter Kiewit Sons' Co. v. Iowa Southern Utilities Co.District Court, S.D. Iowa · 1973
- Schankin v. BuskirkMichigan Supreme Court · 1958
5 more not listed; retrieve them via the Exa API.
3Cited by47 opinions
- David ARCHER, Plaintiff-Appellee, v. MACOMB COUNTY BANK, Defendant-AppellantCourt of Appeals for the Sixth Circuit · 1988
- Schewe v. Fairview Estates (In Re Schewe)United States Bankruptcy Court, W.D. Michigan · 1989
- Matthews v. United States (In Re Matthews)United States Bankruptcy Court, S.D. Alabama · 1995
- In re SeatonUnited States Bankruptcy Court, E.D. Virginia · 2011
- Sands v. United Student Aid Funds, Inc. (In Re Sands)United States Bankruptcy Court, W.D. Michigan · 1994
42 more not listed; retrieve them via the Exa API.