Legal Opinion
Nelse Mortensen & Co. v. Group Health Cooperative
Court of Appeals of Washington
Decided June 6, 1977No. 4034-1PublishedCited by 17 opinions
1Opinion of the CourtPearson, J.
Group Health Cooperative of Puget Sound (Group Health) appeals from a judgment totalling $614,782.77 for damages due to delays in the remodeling and construction of additions to Group Health Hospital in Seattle. The judgment was awarded to the construction project's general contractor, Nelse Mortensen & Co. (Mortensen), and to subcontractors Berg Plastering, Inc. (Berg), Industrial Electric-Seattle, Inc. (Industrial Electric), and W. L. Henson Co., Inc. (Henson), on a theory of semitortious interference by Group Health with the contractors' performance of their work under the contract. The…
2Cases cited9 opinions
- Bignold v. King CountyWashington Supreme Court · 1965
- Bowman v. WebsterWashington Supreme Court · 1953
- V. C. Edwards Contracting Co. v. Port of TacomaWashington Supreme Court · 1973
- Ericksen v. Edmonds School District No. 15Washington Supreme Court · 1942
- Goss v. Northern Pacific Hospital Ass'nWashington Supreme Court · 1908
4 more not listed; retrieve them via the Exa API.
3Cited by17 opinions
- Interlake Porsche + Audi, Inc. v. BucholzCourt of Appeals of Washington · 1986
- CKP, Inc. v. GRS Construction Co.Court of Appeals of Washington · 1991
- Lyall v. DeYoungCourt of Appeals of Washington · 1985
- Modern Builders, Inc. v. MankeCourt of Appeals of Washington · 1980
- CHRISTIANSEN BROTHERS v. StateWashington Supreme Court · 1978
12 more not listed; retrieve them via the Exa API.