SM 10000 Property, LLC v. Allianz Global Risks US Insurance Company

1 2 3 4 5 6 7 8 UNITED STATES DISTRICT COURT 9 NORTHERN DISTRICT OF CALIFORNIA 10 San Francisco Division 11 SM 10000 PROPERTY, LLC, et al., Case No. 19-cv-03054-PJH (LB) 12 Plaintiffs, DISCOVERY ORDER 13 v. Re: ECF No. 55 14 ALLIANZ GLOBAL RISKS US INSURANCE COMPANY, 15 Defendant. 16 17 This case involves the extent of Allianz’s responsibility under the parties’ insurance contract 18 for the delay that resulted from an accident at the plaintiffs’ construction contract.1 The parties 19 have three disputes: (1) whether the attorney-client privilege protects withheld documents 20 reflecting…