Introducing ATLASLearn more
Legal Opinion

Siemens Westinghouse Power Corp. v. Dick Corp.

District Court, S.D. New York

Decided October 14, 2003No. 03 Civ. 364(VM)PublishedCited by 6 opinions

1Opinion of the Court

DECISION AND ORDER

MARRERO, District Judge.

Plaintiff Siemens Westinghouse Power Corporation (“SWPC”) and defendant Dick Corporation (“Dick”) formed a Consortium for the purpose of constructing a power plant in New Hampshire on behalf of global power company AES Corporation (“AES”). Because of delays in the project, SWPC has allegedly paid over $18 million in liquidated damages to AES. SWPC filed a complaint seeking reimbursement for those payments from Dick and from Dick’s sureties, defendants Continental Casualty Company and National Fire Insurance Company of Hartford (collectively, the…

2Cases cited9 opinions

  1. Anderson v. Liberty Lobby, Inc.Supreme Court of the United States · 1986
  2. Goldman v. BeldenCourt of Appeals for the Second Circuit · 1985
  3. Cosmas v. HassettCourt of Appeals for the Second Circuit · 1989
  4. Burlington Coat Factory Warehouse Corporation v. Esprit De Corp. And Federated Department Stores, Inc.Court of Appeals for the Second Circuit · 1985
  5. John Hancock Mutual Life Insurance v. Harris Trust & Savings BankSupreme Court of the United States · 1993

4 more not listed; retrieve them via the Exa API.

3Cited by6 opinions

  1. Siemens Westinghouse Power Corp. v. Dick Corp.District Court, S.D. New York · 2004
  2. Siemens Westinghouse Power Corp. v. Dick Corp.District Court, S.D. New York · 2004
  3. Siemens Westinghouse Power Corp. v. Dick Corp.District Court, S.D. New York · 2004
  4. Siemens Westinghouse Power Corp. v. Dick Corp.District Court, S.D. New York · 2004
  5. Siemens Westinghouse Power Corp. v. Dick Corp.District Court, S.D. New York · 2004

1 more not listed; retrieve them via the Exa API.

Showing a preview — retrieve the full document via the Exa API.

View API DocsGet API Key

Powered by the Exa API