Hanrahan v. Audubon Builders, Inc.

HUDOCK, Judge.

Audubon Builders, Inc., and both James and Audubon Brink, as individuals, (Appellants) appeal from an order of the Court of Common Pleas directing them to pay an amount of $150 per day for each day from February 15, 1988 to December 22, 1988 in liquidated damages resulting from delays in completion of a construction project at the home of Frank and Marie Hanrahan (Appellees). We vacate and remand in part and affirm in part.

The facts and procedural history may be summarized as follows: On November 21, 1987, Appellant James Brink, as president of Appellant Audubon Builders, Inc.,…