Legal Opinion
Ragan Enterprises, Inc. v. L & B Construction Co.
Court of Appeals of Georgia
Decided September 20, 1996No. A96A0566PublishedCited by 4 opinions
1Opinion of the Court
Birdsong, Presiding Judge.
Ragan Enterprises, Inc. (“REI”), a subcontractor on a construction project, filed suit against the general contractor, L & B Construction Company, Inc. and its surety for breach of contract caused by L & B’s two-year delay in completion of the project.
REI and L & B filed cross-motions for partial summary judgment on the issue of whether the subcontract contains a “no damages for delay” clause. REI contends this clause does not bar it from recovering damages for delay: “Should subcontractor be delayed in his work by contractor then contractor shall owe subcontractor…
2Cases cited4 opinions
- Department of Transportation v. Arapaho Construction, Inc.Court of Appeals of Georgia · 1986
- Redman Development Corp. v. Piedmont Heating & Air Conditioning, Inc.Court of Appeals of Georgia · 1973
- Department of Transportation v. APAC-Georgia, Inc.Court of Appeals of Georgia · 1995
- Centex-Rodgers Constr. Co. v. McCANN STEEL CO. INC.Court of Appeals of Georgia · 1992
3Cited by4 opinions
- Altama Delta Corp. v. HowellCourt of Appeals of Georgia · 1997
- L & B Construction Co. v. Ragan Enterprises, Inc.Supreme Court of Georgia · 1997
- Bernotas v. Super Fresh Food Markets, Inc.Superior Court of Pennsylvania · 2002
- Ragan Enterprises, Inc. v. L & B Construction Co.Court of Appeals of Georgia · 1997