Legal Opinion
Centex-Rodgers Constr. Co. v. McCANN STEEL CO. INC.
Court of Appeals of Georgia
Decided November 30, 1992No. A92A1300PublishedCited by 4 opinions
1Opinion of the Court
Cooper, Judge.
In July 1989, appellant entered into a contract with the City of I Roswell (the “City”) for the construction of the Roswell Municipal Center. The contract was a standard American Institute of Architects (“AIA”) contract (the “contract”), which required the contractor to incorporate the terms of the contract into each subcontract and to require each subcontractor to be bound by the contract and assume toward the contractor all obligations which the contractor assumed toward the owner. The contract contained a liquidated delay damages paragraph, which provided that if appellant…
2Cases cited3 opinions
- Binswanger Glass Co. v. Beers Construction Co.Court of Appeals of Georgia · 1977
- Home Insurance Co. v. North River InsuranceCourt of Appeals of Georgia · 1989
- Spalding Construction Co. v. SimonCourt of Appeals of Georgia · 1927
3Cited by4 opinions
- Ferdinand v. City of East PointCourt of Appeals of Georgia · 2009
- Ragan Enterprises, Inc. v. L & B Construction Co.Court of Appeals of Georgia · 1996
- Centex-Rodgers Construction Co. v. City of RoswellCourt of Appeals of Georgia · 1994
- Hunnings v. Travelers Insurance Group Holdings, Inc.District Court, S.D. Georgia · 2020