Quin Blair Enterprises, Inc. v. Julien Construction Co.

RAPER, Chief Justice.

The principal questions raised in this appeal concern appropriate damages for delay in completing a building contract, the effect of a contractual provision requiring the contractor to request in writing an extension of time to complete the contract, the effect on other contract remedies of an escrow agreement and a “punch-list” which required the contractor to redo work that was incorrectly or defectively done, and the ef-feet of a failure to timely serve notice of suit upon a surety-defendant whom plaintiff alleges is united in interest with the contractor-defendant.

The…