Legal Opinion
Donald H. Rumsfeld, Secretary of Defense v. Freedom Ny, Inc., Freedom Ny, Inc. v. Donald H. Rumsfeld, Secretary of Defense
Court of Appeals for the Federal Circuit
Decided May 22, 2003No. 02-1105, 02-1130PublishedCited by 84 opinions
1Opinion of the Court
DYK, Circuit Judge.
The Secretary of Defense (“government”) appeals the Armed Services Board of Contract Appeals’ (“Board’s”) decision holding invalid two settlement agreements (Modifications 25 and 29) between the government and the contractor and awarding a price adjustment pursuant to the “Government Delay of Work” clause in the contract. Freedom NY, Inc., ASBCA No. 43965, 01-2 B.C.A. (CCH) ¶'31,585 at 156,-043, 2001 WL 1143312 (2001). Freedom New York, Inc. (“contractor”) cross appeals the Board’s decision declining to find a cardinal change, bad faith, or constructive change (based on the…
2Cases cited31 opinions
- Consolidated Edison Co. v. National Labor Relations BoardSupreme Court of the United States · 1938
- United States v. Winstar Corp.Supreme Court of the United States · 1996
- McAbee Construction, Inc. v. United StatesCourt of Appeals for the Federal Circuit · 1996
- William O. Schism and Robert Reinlie v. United StatesCourt of Appeals for the Federal Circuit · 2002
- United States v. Bethlehem Steel Corp.Supreme Court of the United States · 1942
26 more not listed; retrieve them via the Exa API.
3Cited by84 opinions
- Centex Corp. v. United StatesCourt of Appeals for the Federal Circuit · 2005
- Textron, Inc. v. United StatesUnited States Court of Federal Claims · 2006
- Barron Bancshares, Inc. v. United StatesCourt of Appeals for the Federal Circuit · 2004
- J.A. Jones Construction Co. v. Lehrer McGovern Bovis, Inc.Nevada Supreme Court · 2004
- Barron Bancshares, Inc. v. United StatesCourt of Appeals for the Federal Circuit · 2004
79 more not listed; retrieve them via the Exa API.