Legal Opinion
Foster & Creighton Co. v. Wilson Contracting Co.
Court of Appeals of Tennessee
Decided October 27, 1978PublishedCited by 30 opinions
1Opinion of the Court
OPINION
TODD, Judge.
The plaintiff, Foster & Creighton Company, a subcontractor, sued its general contractors, R. B. Tyler Company, Inc. (now known as Wilson Contracting Company) and Tyler-Hyde Company, a joint venture, for damages representing extra expenses incurred by delay of and interference with plaintiff in completing its subcontract. Defendants filed a third party action against United States Fidelity and Guaranty Company, surety on the contract of another subcontractor, T. F. Scholes, asserting that plaintiff’s damages, if any, were due to the default or delinquency of Scholes and that…
2Cases cited3 opinions
- V. C. Edwards Contracting Co. v. Port of TacomaWashington Supreme Court · 1973
- Wright & Kremers, Inc. v. StateNew York Court of Appeals · 1934
- Cherokee Insurance Co. v. United States Fire Insurance Co.Court of Appeals of Tennessee · 1977
3Cited by30 opinions
- McClain v. Kimbrough Const. Co., Inc.Court of Appeals of Tennessee · 1990
- Siddarth Shah and Daksha Shah, Plaintiffs-Appellants/cross-Appellees v. Racetrac Petroleum Co., Defendant-Appellee/cross-AppellantCourt of Appeals for the Sixth Circuit · 2003
- Moore Construction Co. v. Clarksville Department of ElectricityCourt of Appeals of Tennessee · 1986
- Owen of Georgia, Inc., Cross-Appellant v. Shelby County Roy Nixon, Mayor of Shelby County Pidgeon-Thomas Iron Company, Cross-AppelleesCourt of Appeals for the Sixth Circuit · 1981
- Bill Brown Construction Co. v. Glens Falls Insurance Co.Tennessee Supreme Court · 1991
25 more not listed; retrieve them via the Exa API.