Legal Opinion
Zafer Taahhut Insaat Ve Ticaret, A.S. v. United States
United States Court of Federal Claims
Decided April 3, 2015No. 13-888CPublishedCited by 2 opinions
1Opinion of the Court
Firm Fixed-Price Construction Contract; Delivery of Materials and Supplies to Project Site; Effect of Pakistan Border Closing; Contractor Claim for Equitable Adjustment; Time Extension for Unexpected Delays; Supplementation of Record; Motion to Consolidate.
OPINION AND ORDER
WHEELER, Judge.
This ease arises from a firm fixed-price contract between Plaintiff, Zafer Taahhut Insaat Ve Ticaret, A.S. (“Zafer”) and the United States Army Corps of Engineers to construct a community support facility at the Bagram Air Field in Afghanistan. Under the contract, Zafer was responsible for delivering…
2Cases cited20 opinions
- Anderson v. Liberty Lobby, Inc.Supreme Court of the United States · 1986
- Celotex Corp. v. Catrett, Administratrix of the Estate of CatrettSupreme Court of the United States · 1986
- Sri International v. Matsushita Electric Corporation of America and Matsushita Electric Industrial Co., Ltd.Court of Appeals for the Federal Circuit · 1985
- Centex Corp. v. United StatesCourt of Appeals for the Federal Circuit · 2005
- Am-Pro Protective Agency, Inc. v. United StatesCourt of Appeals for the Federal Circuit · 2002
15 more not listed; retrieve them via the Exa API.
3Cited by2 opinions
- Zafer Taahhut Insaat Ve Ticaret A.S. v. United StatesCourt of Appeals for the Federal Circuit · 2016
- Villars v. United StatesUnited States Court of Federal Claims · 2016