J. R. Graham & Son, Inc. v. Randolph County Board of Education

ARNOLD, Judge.

Defendant contends that the contract documents, including the standard AIA contract, preclude plaintiff’s recovering the relief granted by the trial court. Upon a voluminous record, the court made detailed findings of fact. It is for this Court to inquire whether these findings are supported by the evidence and whether they support the conclusions of law.

The North Carolina Supreme Court has said:

“Obviously, as an elementary general proposition, a contractor is not liable under a clause for liquidated damages based on a time limit if his failure to complete the contract within…