Vanderlinde Electric Corp. v. City of Rochester
Appellate Division of the Supreme Court of the State of New York
1Opinion of the CourtDillon, J.
Defendant appeals from an order of Special Term denying its motion to dismiss plaintiffs complaints for failure to state causes of action (CPLR 3211, subd [a], par 7), and on the ground that its defense is founded upon documentary evidence (CPLR 3211, subd [a], par 1). The complaints allege that defendant’s unreasonable interference delayed completion of work on two projects under construction contracts, and seek damages caused by the delay.
On September 30, 1970 the parties entered into a written contract for the performance of electrical and instrumentation work on the additions to the…
2Cases cited16 opinions
- Hartford Accident & Indemnity Co. v. WesolowskiNew York Court of Appeals · 1973
- Wilson Trading Corp. v. David Ferguson, Ltd.New York Court of Appeals · 1968
- Taylor v. State of New YorkNew York Court of Appeals · 1951
- Cauldwell-Wingate Co. v. StateNew York Court of Appeals · 1938
- Waterman v. StateAppellate Division of the Supreme Court of the State of New York · 1963
11 more not listed; retrieve them via the Exa API.
3Cited by6 opinions
- Blackrock Capital Investment Corp. v. Jerry FishWest Virginia Supreme Court · 2017
- M. D. Lundin Co. v. Board of EducationAppellate Division of the Supreme Court of the State of New York · 1979
- Hammond Lane Mechanicals, Inc. v. Village of PotsdamAppellate Division of the Supreme Court of the State of New York · 1991
- Bialo v. Walter Lawlor, Inc.Appellate Division of the Supreme Court of the State of New York · 1990
- Blackrock Capital Investment Corp. v. Jerry FishWest Virginia Supreme Court · 2017
1 more not listed; retrieve them via the Exa API.