Legal Opinion
Port Chester Electrical Construction Corp. v. HBE Corp.
District Court, S.D. New York
Decided October 2, 1991No. 86 Civ. 4617 (KMW)PublishedCited by 2 opinions
1Opinion of the Court
OPINION AND ORDER
NINA GERSHON, United States Magistrate Judge:
This is an action by an electrical subcontractor against a general contractor and its surety for delay damages following completion of a contract for renovations and new construction on the Nyack Hospital in Nyack, New York. Pursuant to the parties’ consent under 28 U.S.C. § 636(c), a bench trial was held before me. This Opinion and Order contains the findings of fact and conclusions of law required by Rule 52(a) of the Federal Rules of Civil Procedure.
The Delays and Their Effect on Port Chester
As a “design/build” contractor,…
2Cases cited19 opinions
- Berley Industries, Inc. v. City of New YorkNew York Court of Appeals · 1978
- Kramer, Levin, Nessen, Kamin & Frankel v. AronoffDistrict Court, S.D. New York · 1986
- Najjar Industries, Inc. v. City of New YorkAppellate Division of the Supreme Court of the State of New York · 1982
- Manshul Construction Corp. v. Dormitory AuthorityAppellate Division of the Supreme Court of the State of New York · 1981
- Whitmyer Bros., Inc. v. StateNew York Court of Appeals · 1979
14 more not listed; retrieve them via the Exa API.
3Cited by2 opinions
- United States Ex Rel. Maris Equipment Co. v. Morganti, Inc.District Court, E.D. New York · 2001
- Port Chester Electrical Construction Corp. v. Hbe Corporation and the Fireman's Fund Insurance CompanyCourt of Appeals for the Second Circuit · 1992