Manshul Construction Corp. v. Dormitory Authority
Appellate Division of the Supreme Court of the State of New York
1Opinion of the Court
OPINION OF THE COURT
Silverman, J.
This action arises out of a construction contract whereby plaintiff Manshul Construction Corp. contracted to do certain work for defendant Dormitory Authority of the State of New York (DASNY) in connection with La Guardia Community College, a division of the City University of New York.
Plaintiff’s complaint had three causes of action—the first for balance due under the contract, the second for reasonable value of extra, changed and/or additional work, and the third for damages essentially for delay due to defendant’s failure to provide adequate access to the…
2Cases cited14 opinions
- Berley Industries, Inc. v. City of New YorkNew York Court of Appeals · 1978
- Whitmyer Bros., Inc. v. StateNew York Court of Appeals · 1979
- Fehlhaber Corp. & Horn Construction Co. v. StateAppellate Division of the Supreme Court of the State of New York · 1979
- Fehlhaber Corp. & Horn Construction Co. v. StateAppellate Division of the Supreme Court of the State of New York · 1978
- Whitmyer Bros., Inc. v. StateAppellate Division of the Supreme Court of the State of New York · 1978
9 more not listed; retrieve them via the Exa API.
3Cited by35 opinions
- S. Leo Harmonay, Inc. v. Binks Manufacturing Co.District Court, S.D. New York · 1984
- Najjar Industries, Inc. v. City of New YorkAppellate Division of the Supreme Court of the State of New York · 1982
- Travelers Casualty & Surety Co. v. Dormitory Authority-StateDistrict Court, S.D. New York · 2010
- United States Ex Rel. Maris Equipment Co. v. Morganti, Inc.District Court, E.D. New York · 2001
- Metropolitan Steel Industries, Inc. v. Perini Corp.Appellate Division of the Supreme Court of the State of New York · 2007
30 more not listed; retrieve them via the Exa API.