Legal Opinion
Gordon R. England, Secretary of the Navy v. The Sherman R. Smoot Corp.
Court of Appeals for the Federal Circuit
Decided November 3, 2004No. 03-1461PublishedCited by 32 opinions
1Opinion of the Court
SCHALL, Circuit Judge.
This case arises under the Contract Disputes Act of 1978 (codified at 41 U.S.C. §§ 601-613 (2000)) (“CDA”). Gordon R. England, Secretary of the Navy (“Navy” or “government”), appeals the decision of the Armed Services Board of Contract Appeals (“ASBCA” or “Board”) awarding The Sherman R. Smoot Corporation (“Smoot”) compensation for a fifty-one-day delay in the completion of Contract No. N62477-94-C-0028 between Smoot and the Navy (the “contract”). In re Sherman R. Smoot Corp., ASBCA No. 53115, 2003-1 B.C.A. (CCH) ¶ 32,198, 2003 WL 715267 (Feb. 25, 2003). The government…
2Cases cited18 opinions
- Reflectone, Inc. v. John H. Dalton, Secretary of the NavyCourt of Appeals for the Federal Circuit · 1995
- Community Heating & Plumbing Company, Inc. v. Admiral Frank B. Kelso, Ii, Acting Secretary of the NavyCourt of Appeals for the Federal Circuit · 1993
- J. D. Hedin Construction Company, Inc., for Its Own Use and for the Use of Fischbach & Moore, Its Sub-Contractor v. The United StatesUnited States Court of Claims · 1965
- Melvin Wilner, D/B/A Wilner Construction Company v. United StatesCourt of Appeals for the Federal Circuit · 1994
- The Sharman Company, Inc. v. United StatesCourt of Appeals for the Federal Circuit · 1993
13 more not listed; retrieve them via the Exa API.
3Cited by32 opinions
- R. Edward Bates, Claimant-Appellant v. R. James Nicholson, Secretary of Veterans AffairsCourt of Appeals for the Federal Circuit · 2005
- Southern Nuclear Operating Co. v. United StatesUnited States Court of Federal Claims · 2007
- George Sollitt Construction Co. v. United StatesUnited States Court of Federal Claims · 2005
- Redland Co. v. United StatesUnited States Court of Federal Claims · 2011
- Renda Marine, Inc. v. United StatesUnited States Court of Federal Claims · 2005
27 more not listed; retrieve them via the Exa API.