Legal Opinion
Great Plains Equipment, Inc. v. Northwest Pipeline Corp.
Idaho Supreme Court
Decided March 29, 1999No. 22762, 22973PublishedCited by 41 opinions
1Opinion of the CourtWalters, Justice
NATURE OF THE CASE
This is an appeal from a judgment in favor of several claimants involved in the construction of a natural gas transmission pipeline. The construction contract was entered into by Northwest Pipeline Corporation (NWP) and Great Plains Pipeline Construction, Inc. (GPPC), and required GPPC to build a new pipeline, compressor pumping stations and related facilities between Pocatello and Burley, Idaho. Delays in the completion of the contract forced GPPC to quit the job, leaving numerous subcontractors, equipment lessors, insurance providers, and other vendors unpaid. GPPC…
2Cases cited40 opinions
- Riverside Development Co. v. RitchieIdaho Supreme Court · 1982
- Farm Credit Bank of Spokane v. StevensonIdaho Supreme Court · 1994
- Friel v. Boise City Housing AuthorityIdaho Supreme Court · 1994
- Harris v. State, Dept. of HealthIdaho Supreme Court · 1992
- Brand S Corp. v. KingIdaho Supreme Court · 1981
35 more not listed; retrieve them via the Exa API.
3Cited by41 opinions
- Axenics, Inc. v. Turner Construction Co.Supreme Court of New Hampshire · 2013
- Great Plains Equipment, Inc. v. Northwest Pipeline Corp.Idaho Supreme Court · 2001
- Vanderford Co., Inc. v. KnudsonIdaho Supreme Court · 2007
- Bakker v. Thunder Spring-Wareham, LLCIdaho Supreme Court · 2005
- Electrical Wholesale Supply Co. v. NielsonIdaho Supreme Court · 2001
36 more not listed; retrieve them via the Exa API.